Germany: DIS40 Spring Conference 2019: The Nuts And Bolts Of Construction Arbitration

Last Updated: 23 August 2019
Article by Pascal Wagenführ

I. Introduction

On 9.4.2019, the DIS40 Spring Conference took place in Bonn with the topic "The Nuts and Bolts of Construction Arbitration – From a lawyer's, expert's and in-house counsel's perspective".1 The conference was moderated by Dr. Annabelle Möckesch (Schellenberg Wittmer) and Dr. Benjamin Lissner (CMS Germany). The conference was divided into two workshops on the topics "How to deal with delay" and "Procedural aspects of construction disputes" and ended with a panel discussion.

II. Workshop 1: How to deal with delay

Dr. Tino Schneider, Associate at LALIVE in Zurich, explained the importance of claims for extension of time ("EoT claims") for employers and contractors in construction projects. He presented the topic by using a pipeline project as a hypothetical case in which delays occurred. In this context, Dr. Schneider referred to the distribution of risks between the parties. He explained the importance of model clauses in construction contracts. The parties base tailor-made solutions on these clauses to achieve legal certainty, as many national legal systems hardly regulate the EoT. The Fédération Internationale des Ingénieurs Conseils (FIDIC) provides model clauses in its so-called "FIDIC Books". Dr. Schneider used Art. 8.5 of the FIDIC Red Book2 as an example and explained its requirements for an EoT. The contractor is entitled to such an EoT for example, if the employer changes the scope of services or in the event of delays or hindrances attributable to the employer. In the further course of his presentation, Dr. Schneider dealt, on the one hand, with the regulations on an EoT under several national legal systems. On the other hand, he highlighted further special topics on the EoT such as the critical path of a project and how to deal with concurrent delays.

Daniel A. Correa, Managing Director at DAC Consulting Services in London, gave a presentation on the different methods for determining delays in construction projects, namely "as-planned vs. as-built", "as-planned impacted", "collapsed as-built" (also "as built but for"), "time impact" and "windows analysis". Correa stressed that there is no method that is suitable for all cases. Moreover, the selection of a suitable method depends on many factors. On the one hand, it is decisive whether the analysis should be carried out prospectively or retrospectively. On the other hand, the regulations of the project contract, the size of the project and the available time as well as the project records are crucial. Based on practical experience, fact-based methods should be preferred over those with hypothetical assumptions. In addition, Correa recommended involving a delay expert as early as possible and putting him or her in direct contact with the client's project managers or key personnel. The parties already involved in arbitration should try to agree on the facts on which their experts can base their analysis upon. This would reduce the complexity of the analysis and make it easier for the arbitral tribunal to assess the case.

Emma Niemistö, a partner at Merilampi Attorneys at Law in Helsinki, gave a lecture on the topics of the EoT and the "Quantum" or claims for damages and remuneration. The legal assessment of the respective claims should be made separately for each claim. The requirement to conduct individual analyses can result from the contractual provisions or from the legal stipulations on which a project is based. Niemistö gave some practical examples and references to Finnish law in her presentation. She examined how to determine if a delay occurred and to what extent. Based on the contractor's original plan, she highlighted the role of consultants, for example, in identifying inefficiencies. She also emphasized the importance of recording the progress of the project as comprehensively as possible. In this way, the client can more effectively refute arguments of the other party with facts.

III. Workshop 2: Procedural aspects of construction disputes

Christina Täuber, Legal Counsel at CML Construction Services GmbH, i. e. STRABAG SE, focused her presentation on a central, but often neglected part of project management, namely the compliance with contractual and legal notification obligations. Often, notifications are either not delivered or delivered incorrectly. The latter happens, for example, if no follow-up takes place in a multi-stage notification process. Täuber substantiated this statement with some practical examples, which illustrated the situation of project managers. Based on these practical examples, she identified two main reasons for the non-compliance with notification requirements. Firstly, notification obligations are regularly simply forgotten during the project execution, as the project managers focus rather on the implementation of the project. Secondly, all participants are interested in a speedy implementation of the project and, in particular, in the early phases of the project, the collaboration is smooth and constructive. Since it is in the interest of the project managers, they avoid notifications in order not to damage the good working relationship with the project partners. Täuber also addressed the requirements for notifications and the consequences of non-compliance. The latter ultimately depends on the origin of the respective obligation. For example, notification requirements under statutory law arise primarily to prevent the limitation of claims, whereas the non-compliance with contractual notification obligations can ultimately cause a preclusion of the claims in question. Täuber gave some valuable practical advice on how to deal with notification obligations in a project. Inter alia, all notification obligations should be identified before the start of the project and included in a practice guide for those responsible for the project. All claims arising during the course of the project should be included in an overview in order to enable effective control of the corresponding notification obligations. As further practical advice, Täuber recommended consulting with a legal advisor before answering the other party's assertion that a notification obligation had not been complied with. Additionally, minutes of meetings provided by the other party should always be read thoroughly before being signed.

Philipp Duncker, Counsel at Hogan Lovells in Munich, examined different mechanisms for pre-arbitral dispute resolution in construction disputes. He focused, inter alia, on negotiation, mediation and adjudication mechanisms. Construction contracts often contain provisions according to which the parties have to undertake an attempt to settle disputes by way of negotiation. Duncker recommended setting an expiry date for negotiations to prevent unfair delay by the other party. The parties may also commit themselves to attempt mediation under the project contract. The parties' negotiations are then guided by a neutral expert or mediator. However, the mediator is not authorised to make a binding decision on the subject matter of the dispute. The parties may also undertake to carry out adjudication based on the provisions of the project contract. This can be done by a single adjudicator or a Dispute Adjudication Board (DAB) with several members, whose selection depends on the circumstances of the case, namely the volume and the technical complexity of the project. The adjudicator or the DAB may make a decision which is binding on the parties, the non-compliance with which constitutes a breach of contract. Even if the decision does not have any formal binding effect on subsequent proceedings, it could still have a certain informal steering effect on the subsequent decision or even set a precedent.

Dr. Lisa B. Reiser, Associate at Baker McKenzie in Frankfurt am Main, highlighted three key factors for the successful management of construction arbitration. A first key factor are the people involved in the project. Major projects are a "people's business" crucially based on the performance of the involved individuals. In this respect, Dr. Reiser recommended an early kick-off meeting in order to determine the essential elements of the dispute. This is crucial because sometimes the project documentation does not show important and decisive details. Such a kick-off meeting can also be used to form the project team and assign responsibilities to the individuals involved. A second key factor for successful construction arbitration is a planned, structured and controlled approach. In order to cope with the enormous effort involved in construction arbitration, it has proved to be useful to define work packages for certain activities and to assign responsibilities under these packages to individual persons. Ultimately, visualization plays a central role for successful construction arbitration. In particular, factual connections or causalities, but also technical systems and functionalities, could be made accessible much easier by using pictures, videos and even miniature models.

IV. Summary

Construction disputes are often resolved in the course of arbitration.3 At the same time, the resolution of such disputes shows unique features compared to regular arbitration. The DIS40 Spring Conference in Bonn offered a valuable insight into this fascinating area of practice. The different perspectives of a lawyer, an expert and an in-house counsel made it possible to look outside the box and gain a broader understanding of the subject matter.


1. The report of the previous DIS40 Spring Conference 2018 can be found in SchiedsVZ 2018, 365.

2. Officially, the FIDIC Red Book is called "Conditions of Contract for Construction". Unofficially, the FIDIC Books are named according to their cover color.

3. Approximately 23 % of all cases brought before arbitral tribunals of the International Chamber of Commerce in 2017 were construction-related, see ICC Disp. Resol. Bull. 2018 Vol. 12/2, 61.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions